SlideShare uma empresa Scribd logo
1 de 9
Baixar para ler offline
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 340
STUDY ON PROCUREMENT METHOD SELECTION PROCEDURE IN
CONSTRUCTION INDUSTRY
Chandrashekhar R. Patil1, Prof. Mahaboobali Nadaf2
1Student M.Tech(Construction Technologgy), Chandrashekhar R. Patil, Dept. of Civil Engineering,
Jain College of Engineering, Belagavi, Karnataka,India
2 Asst.Professor Mahaboobali Nadaf, Dept. of Civil Engineering, Jain College of Engineering,
Belagavi, Karnataka, India
---------------------------------------------------------------------***---------------------------------------------------------------------
Abstract - This Project helps in selection of appropriate
procurement method in the construction industry to achieve
the requirements and needs of the clients and gives more
detailed information about the how does the procurement
system involved in the construction industry.
This study consists of different procurement methods like
traditional, design & build and management procurement,
comparison of different procurement systems, influencing
factors, effecting factors, key actions, variables , theoretical
frame work, mechanism for analyzing the different
procurement system, development of procurement strategy,
advantages , detailed method selection procedure and case
study. Brief study has carried out in the project work; about
the procurement method selection procedure.
Key Words: Procurement, Variables, Frame Work,
Mechanism, Case Study
1.INTRODUCTION
A procurement system can be defined as “an organizational
system that assigns specific responsibilities and authorities
to people and organizations, and defines the various
elements in the construction industry”. It is not only
applicable to developed market economics, but also
construction industry development in less advanced
economy.
The procurement system benefits the organization to
manage procurement process effectively and efficiently in
construction industry. The system canassistanorganization
to achieve successful outcome for their project with
necessary guidance and support. It will also control therisks
involved in the construction industry and minimize the cost
variation problems.Theprocurementsysteminconstruction
industry is useful in following ways:
 It helps in preparing tender documents and
contracts
 Selection of contractors and consultants based on
their earlier records
 This system includes checklist for effective
maintenance of the contract
 It increases the efficiency and effectiveness of the
management system by constant monitoring and
reporting
 The disputes arising are resolved with help of this
system
Procurement advice an appropriate contracting strategy,
offering and preparation of tender documents, choice of
experts and contractors, contract organizationandavoid the
un-necessary discussions
1.1 Objectives of procurement system
The goal of the procurement systemisforsuccessful
completion and implementation of the project. Some of the
objectives are mentioned below:
 To carry out justifiably and truthfully
 Perform assigned work in timely manner with
honesty
 Have to Satisfy the all rules of legislation and
principles
 To reach the all requirements of the client’s needs
 Controls construction related dispute
1.2 Procurement activities and key actions
Table-1: Activity and key action
Activity Sub activity Key action
1
Defining the
objectives
for the
procurement
1.1
Organize
wide range
of activities.
To improve the
title for
procurement to
recognize and
define scope of
the project.
1.2
Evaluation
of economic
value for
planned
procuremen
t.
For budgeting,
it is necessary
for evaluation
of the economic
value of the
proposed
contract.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 341
1.3 Scope
This study helps in establishing a construction procurement
system for:
1. Goods, services, engineering andconstructionwork
relating to the construction industry in a fair,
balanced, transparent, competitive and cost
effective manner.
2. It deals with procurement methods which help to
proper implementation and successful completion
of the project as per client requirements.
3. It accomplishes future requirements, and develops
the industry to give early and best adorable results
to the clients with respect to cost, quality and time.
1.4 Objectives of the study
Main objectives of the present project work are as follows:
1) Study of various procurement methods involved in the
construction industry
2) To determine factors influencing the selection of
procurement systems in construction industry
3) Mechanism for analyzing the different procurement
system
4) Procedure to develop and implement a procurement
strategy
5) To determine the suitable procurement method for Dr.
Prabhu Halakatti hospital building, Belagavi
2. METHODOLOGY
By referring different literatures, technical reports, case
study and other resources related to the current study, an
outline of the methodology of the present work has been
discussed briefly below, to achieve the objectives of the
project.
• Study involves different methods of procurement
system, influence of procurement methods on
project performance, mechanism for analyzing
different procurement system, procedure to
develop and implement a procurement strategy
• Comparison of different procurement systems and
their advantages
• Based on the studies, proposal have made on Dr.
Prabhu Halakatti hospital building carried out
during the period of internship, problems are
analyzed and solved with the procurement system
and few suggestions are made.
2.1 Procurement systems
Different methods of procurements are
a. Traditional
b. Design and construct
c. Management
a. Traditional procurement method:Itistheoldesttypeof
construction procurement as well as one of the most
common types of procurement method. It is defined as a
project delivery strategy, wherein two different companies
will carry out all project processes.
Contracts are mainly divided in to three types
Lump sum contracts: Prior to the starting the construction
project, the contract amount is determined with consulting
various stakeholders. The amount of Lump sum contracts is
decided on the basis of bill of quantities and thing which is
not able to find can be found by accurate evaluation
Measurement contracts: Here, only after thecompletionof
the project and re-measurement, the precise amount is
known and it is additionally alluded towards as re-
quantification contracts.
Cost reimbursement: It is as well recognized as cost plus
contracts, wherein the contract amount is calculated based
on actual cost of labour and materials also the profit and
overhead charges are considered.
Advantages of traditional procurement
 Help full for the contractor to apply for the tender
on the same premise.
 Client can have immediate impact which can
encourage high state of usefulness and enhance the
quality in the design.
Circumstances in which traditional procurement to be
used are
 Wherein the design consultant is necessary.
 The designers and contractors are hired
independently.
 If superiority of the work is essential for the clients.
b. Design and Construct Procurement: Here,theclientwill
give all needs desires for the project and assigns different
task to the contractor. The association of the D&C methods
and relative freedom of the contractor helps the client in
obtaining the best price for the project, which may lead to
cost benefits.
Advantages of design and construct procurement
 Client can deal properly with one firm
 Overlap of design and construction performance
will minimize the project time
CircumstancesinwhichD&Cprocurementtobeusedare
 When project does not require any specialized
development
 Design scope is likely to change
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 342
 When project is technically difficult to understand
c. Management Procurement system: This consists of
management contracting and construction management.
Management contracting: The management contractor is
working with the clients. The contractors are involved at
every stage of the construction and are responsible for
works that are executed with direct contracts. Due to its
flexibility, this type of contracts allow the clients to change
the design during the construction process as well as the
project can be started early and completed on time.
Construction management: A contractor will pay amount
as per the completely to control, build up a schedule and
arrange the outline and development exercises, The
administration contractual worker is chosen later than a
vigilant determination procedure and is paid via
administration prise.
Various advantages have been recognized on CM approach
summarized as follows
 Construction management expertise involve met in
the beginning of the project
 Overlap of design and construction
2.2 Factors influencing the selection of
procurement systems in construction industry
External environment: Factors from the external
environment consist of variables like market competition,
information technology, regulatory environment, natural
causes and globalization, politics, finance etc.
Internal environment: This can be divided under three
main factors such as project characteristics, client’s
characteristics andclient’srequirement.Clientrequirements
can be sub-divided into cost related factors, time related
factors and quality related factors.
Some of the important factors mainly influence while
choosing of procurement system arebrieflyexplained below
a) Socio–economic thought: It has derived from the four
factors: political thought, government (public) or private
segment venture, market or monetary condition and
developing innovation.
b) Client requirements: This factor incorporates:
customer's particular prerequisites, political obstructions,
globalization and customer's level of information.
c) Capital cost/cash flow: This Factor clarifies the total
variation; in any case, it is hard to clarify this component,
since just a single variable impact upon it. Customer and fee
related variable. If this componentmeasurescapital cost,itis
identified with factors of customer necessities variables.
d) Project characteristics: This Factor is obtained from
variance that clarifies the total fluctuation. In particular,
impact of the life cycle on venture, range and technical
complexity of the venture.
2.3 A theoretical framework on influence of
procurement methods on project performance
Fig. 1 shows, a theoretical system that simplifies, the
acquisition choice criteria, in order to help in discovering
their effects on construction execution. All of the certainty
would affect distinctively on duration, price and quality,
dependent upon the appropriateness of the details as for a
given acquirement technique.
The level of impact of every fact on given venture can be
dictated by allocating with a use of number utilizing a range
of 1-7, where 1-3 demonstrates pessimistic impact on
execution and 5-7 shows optimisticimpact,4asnoimpactor
nonpartisan.
Fig-1: Theoretical framework
2.4 Mechanism for analyzing the different
procurement systems
This settled structure clarifies and investigation both hard
and flexible parts of authoritative administration, for
example, procedure, structure, frameworks, shared values,
staff and skills. It is additionally firmly related and
appropriate to a venture conveyance approach,asthemodel
is perceived for its all necessaries and substantial extension.
The details of the Seven S Model and its extension and
clarification for the construction project are:
 Strategy: Describes as an arrangement in
dispensing assets to accomplish recognized
objectives at the time.
 Structure: It characterizes a framework for the
organization. Though, in construction project level,
it is about the general venture delivery system,
especially to organize the undertakings involved
and its procedure of administration.
 Systems: These are the standard procedures and
methods followed within the association. It is
comparative for the extent of works and
employment exercises at the venture level.
 Shared esteems: It eludes to the noteworthy
implications or managing ideas that authoritative
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 343
individuals share. The way of life of the overall
management would decide the common values
produced from alternate models at the venture
level.
 Staff: Describes as work force classes within the
organization. This identifies with the level of
capacities required for the workforce at the project
level.
 Skills: It alludes to the genuine level of abilities and
capabilities of the representatives working for the
organization. In the development setting, it is about
the level of specialization required for the project
delivery approach.
2.5 Procurement Strategies
Procurement technique, which is regularly created amidthe
assessment periods of a venture, is a key component for
effective venture conveyance.
The acquisition system is a core venture document, which
shows the result of an exact acquirement alternative
assessment undertaken by the project proprietor, to
differentiate the suggested conveyance model and
procurement technique for a venture while considering the
venture's individual qualities, risk and conditions
To build up a powerful acquirement methodology, it is
critical to
 Thoroughly comprehend the venture including key
drivers, imperatives and dangers
 Determine organization and market abilities and
limit
 Involve key partners and specialists at right time in
the arranging and improvement process
2.5.1 Procedure to develop and implement a
procurement strategy
Appropriatelyprogramming theimprovementandexecution
of the acquisition methodology with financing viewpoint, is
the piece of good venture administration, as further
discussed below.
a) Informing the funding decision: It is essential that the
procurement system is created in an opportune way, as
offices might be required to present the points of interest of
acquisition alternatives under contemplations to
organizations, as a feature of the business case, in help of a
speculation choice for the project. Last acquisition
methodology will likewise should be endorsed by
association before conveyance of the project.
In creating acquirement procedures, the proprietors must
permit adequate time for a capable investigation of all
accessible obtainment alternatives, approval activities and
surveys, and association endorsements.
Organization will have their own particular procedures for
procurement, to follow so as to get administration approval
for the assumption, and whether this ought to happen at the
same time with a choice on the favored procurement
technique.
b) Programming for development: venture conveyance,It
can be depicted as the procedure by objective of a venture
has acknowledged, it has to boost through a suitable
acquisition strategy, to guarantee the necessary works are
not postponed
Programming the growth of the acquisition strategy is
subsequently significant for a project administration
perspective. To accomplish best possible timing, the
obtainment strategy development process ought to initiate
as right on time as venture lifecycle, as a major aspect of the
venture's assessment and definition stages
c) Programming for implementation: Guideline of the
procurement strategy will usuallystartsattheinitial stageof
the construction venture and it will carry out till the end of
the phase, with that transition to function stage, it will be
conditional on which kind of deliver model has considered.
3. CASE STUDY
A Proposal is made by taking a hospital building as case
study, through studying thevariousdocumentsanddifferent
procurement system.Fromtheobservations,problemsfaced
in the construction project are documented and suggestions
were made for successful completion of project.
Project title : Dr. Prabhu Halakatti Hospital Building
Procurement method used: Traditional Lump Sum
Project Value: Rs. 4, 27, 00,000
Contractor: Anoop Javalkar
Client: Dr. Prabhu Halakatti
Architect: Sangolli and Associates
Project Overview
The choice to add a Traditional Lump Sum procurement
strategy on this venture is intensely affected through the
diverse features of the venture. All things considered,
adequate time and assets were dispensed to ensure definite
plan and determinations has framed.
Moreover, it is an interesting undertaking wherein, the
design and requirements must be precise with particular
criteria. It is consolidated with the TLS strategy for
acquisition proposed to contractual worker with offering of
the venture so that, procurement determination handle for
this venture is moderately straight-forward.
With construction is expected to finish by 2017 with total
cost of Rs 4.27cr. The new heart hospital center will provide
the best heart related treatment accessible in the Belagavi
city and considerably decrease the waiting time forpatients.
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 344
The hospital right now care for around 1200 heart patients
utilizing distinctive treatment every year, with 4000
treatment will visit, the opening of the latestHospital center,
extra 200 heart patients will be there dealt with every year.
Detailed Documentation: More attention on the plan and
design was necessary. Ventures relating to health are more
intricate than the most projects carried out by architects.
Detailed documentation is taken into thought for
expectations works and its coordination into existing
structures was likewise of critical significance. The
acquirement technique embraced for this venture must be
adequate to help the contribution of reasonable advisors.
High Quality End Product: Effect of contributing adequate
duration and assets, in the direction of deliver complete
records at the major stage of plans and particular, this point
of scheduling will deal by means of the coveted necessity
with high quality final result. The significance of a high
quality venture will be highlighted bytheventuresupervisor
A Balance of Risk between Client and Contractor:
Importance of time and assets interested ina completeset of
plans and determinations, among each of the offering that
contractor offers would guarantee a more focused choice
process and value affirmation of the venture.
The TLS strategy, being an attemptedandtriedtechniquefor
acquisition alternative for venture proprietor and the
market encouraged a decent balance of risk between the
customer and contractors.
Problems occurred during construction
 Lagging in supply of deign during construction
progress
 Delay in project due to in-sufficient supply of
materials
 There is not much proper communication between
clients, contractor and management team
 Over run of time due to making changes in designin
middle of construction
 Variation in cost due to market rates andchangesin
material selection by client
 Improper management makes failure of scheduled
plan
Project Procurement Selection Process
The procurement method selection procedureisdetermined
by means of the case project, the project is based on typical
criteria. In this example, the client is the Dr. Prabhu
Halakatti, has given the proposal for new hospital building
with disabilities. Above problems have influenced to choose
suitable procurement method, it is determined with the
following process.
Step 1: Identifying project objectives and constraints
Objectives of projects:
 Proper programmingandphasingshouldbeontime
 Design criteria has to meet the needs of the client
 Projects have to complete within the agreed rate
 There should not be any over run or delay in the
project
 Cost conviction will berequiredprecedinginitiation
of development
Project Constraints:
 Programme Constraints: Well information about
the hospital building designs are prepare for the
entire project to check clearly completion of the
work at the different stages of construction.
 Planning: The design proposition has satisfied the
requirements of the planning experts and local
partners in the advancement.
 Site Availability: The site ought to be accessible in
the best possible area
 Site Condition: Site had clearlysurveyedbeforethe
start of project, by under taking it as a major aspect
of plan improvement.
 Degree of Client Involvement: It is the most
important in the construction management and Dr.
Prabhu Halakatti involvement in the all stages of
construction process.
 Flexibility for Change during Design and
Construction: Design of the building had carried
earlier & found good prise certainty, hence there is
not required to change during the execution stage.
The procurement options examined here and alternative
procurement methods identified based upon preliminary
discussions are:
a. Traditional
b. Design and Build
c. Management
Step 2: Identify Procurement Selection Criteria
Identification of Procurement Selection Criteria carried on
the following basis,
Time: Early completion of the project is necessary
Certainty of time: Project completion time is most
important
Certainty of cost: Firm prise needed before commitment to
construction
Price competition: Selection of the construction team by
price competition as needed
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 345
Flexibility: Variations are needed after work has begun on-
site
Complexity: Building need to be highly specialised,
technologically advanced
Quality: High quality of the product,intermsofmaterial and
workmanship and design concept are required
Responsibility: Client had the more accountabilityfrom the
architecture and cost consultants.
Risk: The transfer of the risk of cost and time slippage from
the client is vital
Step 3: Weightages of Client Criteria and Procurement
Methods
The procurement assessment criterion for the client’sneeds
and for each procurement methods has clearly found below
Table-2: Determination of the importance of client
criteria for the project
Procurement Assessment Criteria
Weig
hting
Time:
Is early completion required? 5
Certainty of time:
Is project completion on time important?
5
Certainty of cost:
Is a firm price needed before any commitment
to construction given?
3
Price competition:
Is the selection of the construction team by
price competition important?
3
Flexibility:
Are variations necessary after work has begun
on-site?
4
Complexity:
Does the building need to be highly specialized,
technologically advanced or highly serviced?
5
Quality:
Is high quality of the product, in terms of
material and workmanship and design concept
important?
4
Responsibility:
Is single point of responsibility to the client
from the designers and cost consultants
desired?
3
Risk:
Is the transfer of the risk of cost and time
slippage from the client important?
2
Table-3: Criteria weighting with respect to procurement
method
Procurement
Assessment
Criteria
Traditional
Procurement
(P1)
D & B
Procur
ement
(P2)
Manageme
nt
Procureme
nt (P3)
Time 3 5 4
Certainty of time 3 5 4
Certainty of cost 2 4 4
Price
competition
4 3 3
Flexibility 4 4 3
Complexity 4 5 4
Quality 3 4 4
Responsibility 2 5 4
Risk 2 3 2
Table-4: Weighted procurement method scoring table
From the above results can say traditional andmanagement
procurement methods are less scored than D&B
procurement method. Hence, D&B can be considered as the
best suitable procurement method for the proper
implementation of the project to get successful out comes as
per client needs.
Procureme
nt
evaluation
criteria
Weig
htage
(W)
Traditiona
l
Procurem
ent
W x P1=
D&C
procurem
ent
W x P2=
Manageme
nt
procurem
ent
W xP3=
Time 5 15 25 20
Certainty of
time
5 15 25 20
Certainty of
cost
3 6 12 12
Price
competitio
n
3 12 9 9
Flexibility 4 16 16 12
Complexity 5 20 25 20
Quality 4 12 16 16
Responsibi
lity
3 6 15 12
Risk 2 4 6 4
Σ =
Rank
106(3) 149(1) 125(2)
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 346
Step 4: Procurement Appropriateness Chart
Below tables gives a suggestion on the suitability of every
choice against the objectives and key criteria for the project.
Table-5: Time
Time
Traditional
Procuremen
t
D&B
Procuremen
t
Managemen
t
Procuremen
t
Completion
date
certainty
Poor Good Average
Traditional procurement takes more time to
complete the project
Ability to
meet
current
programme
Poor Good Average
The program has to give sufficient time for
characterizing the customer’s necessities.
Facility to
phase
constructio
n
Average good Average
Opportunity for contractual worker
contribution to preplanning for staged
conveyance
Table-6: Cost
Cost
Traditional
Procurement
D&B
Procurement
Management
Procurement
Fixing the
total
amount
of the
project
before
making
the any
bonds.
Average Good Average
Conventional technique gives agreatlevelofprice
sureness furnish so as to complete outline is
delivered preceding to offering
Similarly with D&C gives a huge level of rate
assurance giving the customer’s necessities is
completely characterized up to execution phase.
Shifting
of
amount
related
problems
Poor Average Poor
In D&C configuration hazard will howeverremain
with the customer through the plan group. Under
customary frameworks danger of configurationis
held by the customer.
In D&C design risk will however stay with the
client through the design team. Under traditional
systems risk of design is retained by the client.
Focused
offering
in current
market
situations
Average Good Average
The D&C seems, by all accounts, to be the mainly
appealing alternative for the present market
circumstance.
Table-7: Quality
Step 5: Procurement Review Session
Every perspective from the above Table5to7isexaminedat
the procurement review session. The following points were
audited in connection with elective procurementtechniques
accessible:
Client will be monetarily risk hesitant: D&Cwill givemost
significant cost assurance at every key choice period.
Client will discourage late changes: D&C is a lesser
amount of adaptable to tardy changes. Therefore, it is
favoured more. An unmistakable and subtle element of
Client's prerequisites up to proper level will be required.
Programme is essential: For early complete,D&Cwill offer
the best program favourable circumstances.
Quality is vital: D&C technique gives the best chance to
design quality control, atanexpandedcostrisk evaluatewith
D&C. D&C can give a satisfactory level of plan.
Market conditions: A prior approach and prior
participation of the contractor is valuable in present
economic situations.
Partnering: The Client support's partnering arrangements;
D&C will bring early contractual workerparticipationand so
it proposes the most excellent alternative option to
associates.
Preferred Option
The assent favored choice at this stage is a Design and
Construct procurement method. Key contemplationsare the
Quality
Traditional
Procureme
nt
D&B
Procurem
ent
Management
Procurement
Capacity for
temporary
worker to include
an assess plan
improvement.
Average Good Average
Conventional: Contractor hasparticipatedindesign,
it may cause a few issues as far as zones, for
example, buildability. Offering will get huge quality
at points of interest.
D&B: Gives most extreme capacity for contractual
worker to include an incentive in outline.
Adaptable to suit
modify
instructions
Average Average Poor
Development organize changes ought to be stayed
away from while embracing D&C
Single point duty
regarding design
and development
Poor good Average
In customary the outline and development duties
are divided
Capacity to
manage/react to
location
circumstances
Good Good Average
Temporary workers can examine the location
surroundings completely
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 347
possibilities, to achieve the finish of the procurement
method choice in development of project
Advantages
 Ability of the design team and customer to have an
immediate impact. This will achieve a high level of
usefulness and upgrade the nature of the general
design.
 Client is certain about the venture's cost at the
conferring phase of the agreement.
 Differences in the venture are generally simple to
direct.
Limitations
 Incomplete reports and configuration can
compromisecostconviction andincrementtheodds
of troubles that might occur.
 Restricting the contribution of design or arranging
skill from the contractual worker may not be to the
greatest advantage of the venture.
Lessons Learned
 Enough allotment of assets is necessary to
guarantee design and documentationoftheventure
will conclude at the calling for tender phase of the
venture.
 For superlative activities, for example,those related
with health, the traditional method of procurement
gives the customer the choice for alternatives in
expert advisors to help with the outline.
 This can likewise be a convenient procedure and if
the documentation is notfinished,theadvantagesof
cost certainty can be extreme.
Suggestions
 By implementing the D&Cprocurementsystem,one
can achieve the requirements of the client’s andcan
complete the project on time.
 Design and build method give the appropriate
solution for the above problems occurred on
construction organization.
 The procurement system should be used to give
specific responsibility to participants in the
construction project.
 The suitable system must be selected, to complete
the project successfully and efficiently.
4. CONCLUSIONS AND FUTURE SCOPE
 It has proposed, choice of appropriate procurement
method is the beginning step to achieve goals in
construction related projects.
 Mainly, three most three critical parameter of project
performers are Cost, time and quality.
 More effective in monitoring and control to accurate
implementation and to progress the work
 Who are related to the construction industry, they may
be from public or private sector must be well known
about the different procurement system, hence it will
support to get good results
 Client's authentic needs, necessities, destinations and
project objectives should be properly suggested to the
project group, keeping in mind the end goal is to make
proper procurement strategy
 A apparent, common system has to built up at an early
phase of the project which will decide extensively what
has be done, how it has be done, by whom it must be
done, where it have to be done and when it must be
properly finished
 Improved utilize and equivalence of data innovation is
probably going to be the key, all together for
development industry to have the capacity to meet the
administrative, specialized and social difficulties.
 Improving the procurement strategy in building
administration will get more advantages to deal with
workforce, proprietor of the building, and the clients
who are identified with support industry.
Future scope of study
This study can be extended to other procurement system
such as
 E-procurement
 Collaborative
 Joint venture
 Private financing initiative
REFERENCES
1) Associate Prof. Dr. Anuar Alias et al., Selection of
Procurement Method for Building Maintenance
Management
2) Christopher N. Preece, Improving Construction
Procurement Systems Using Organizational
Strategies, Vol. 11, No. 1 (2014).
3) David Baccarini et al., Building Procurement
Methods, Research ProjectNo:2006-034-C-02,June
2008
4) Dissanayaka Sunil et al., Comparing Procurement
And Non-Procurement Related Contributors to
Project Performance, 1998.
5) Mathonsi, M. D. et al., Factors Influencing The
Selection Of Procurement Systems In The South
African Construction Industry ISSN 1993-8233,Vol.
6(10), 14 March, 2012, pp. 3583-3594.
6) Peter Bamford, Buildingand Construction
Procurement Guide, ISBN 978-1-925037-19-7,
International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056
Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072
© 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 348
Austroads Publications Number AP-G92-14(2014),
pp. 56.
7) Shamil Naoum.et al., Critical review ofprocurement
method research in construction Journals, No.6-13
(2015).
8) Zuleha R. Kadima.et al., An Analysis of procurement
procedures on the implementation of government
construction projects in Kenyan public Universities,
ISSN: 2278 – 0211, Vol 2 Issue 11, November, 2013.
BIOGRAPHIES
Mr. Chandrashekhar R. Patil
Pursuing M.Tech (Construction
Technology)
Jain College of Engineering,
Belagavi, Karnataka, India.
Prof. Mahaboobali Nadaf
Guide & Asst. Professor at
Jain College of Engineering,
Belagavi, Karnataka, India.

Mais conteúdo relacionado

Mais procurados

Quality management in construction
Quality management in constructionQuality management in construction
Quality management in constructionselinasimpson0801
 
Single stage design and build method & construction project management
Single stage design and build method & construction project managementSingle stage design and build method & construction project management
Single stage design and build method & construction project managementJohn Constance
 
Specification writting civil construction
Specification writting civil constructionSpecification writting civil construction
Specification writting civil constructiondiasawada12345
 
Professional Practice 1 Assignment
Professional Practice 1 AssignmentProfessional Practice 1 Assignment
Professional Practice 1 AssignmentMelvin Lim
 
CSCM Chapter 9 sl as cscm
CSCM Chapter 9 sl as cscmCSCM Chapter 9 sl as cscm
CSCM Chapter 9 sl as cscmEst
 
Procurement management-plan template
Procurement management-plan templateProcurement management-plan template
Procurement management-plan templateVivek Srivastava
 
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...IRJET Journal
 
Professional practice 1 report
Professional practice 1 reportProfessional practice 1 report
Professional practice 1 reportNgo Jia Haur
 
Guide to Construction Procurement Strategies
Guide to Construction Procurement StrategiesGuide to Construction Procurement Strategies
Guide to Construction Procurement StrategiesSarah Fox
 
Quality Management System at Construction Project: A Questionnaire Survey
Quality Management System at Construction Project: A Questionnaire SurveyQuality Management System at Construction Project: A Questionnaire Survey
Quality Management System at Construction Project: A Questionnaire SurveyIJERA Editor
 
Procurement in construction
Procurement in constructionProcurement in construction
Procurement in constructionMahSobeh
 
Procurement system in the Indian construction industry issues and remedies
Procurement system in the Indian construction industry issues and remediesProcurement system in the Indian construction industry issues and remedies
Procurement system in the Indian construction industry issues and remediesPavitr1203
 
Technical feasibility ppt
Technical feasibility pptTechnical feasibility ppt
Technical feasibility pptChandan Singh
 

Mais procurados (20)

Quality management in construction
Quality management in constructionQuality management in construction
Quality management in construction
 
Session 19 4th edition PMP
Session  19 4th edition PMPSession  19 4th edition PMP
Session 19 4th edition PMP
 
Procurement Methods
Procurement MethodsProcurement Methods
Procurement Methods
 
Procurement plan-template-1.2
Procurement plan-template-1.2Procurement plan-template-1.2
Procurement plan-template-1.2
 
Single stage design and build method & construction project management
Single stage design and build method & construction project managementSingle stage design and build method & construction project management
Single stage design and build method & construction project management
 
Specification writting civil construction
Specification writting civil constructionSpecification writting civil construction
Specification writting civil construction
 
Session 20 4th edition PMP
Session 20 4th edition PMPSession 20 4th edition PMP
Session 20 4th edition PMP
 
Professional Practice 1 Assignment
Professional Practice 1 AssignmentProfessional Practice 1 Assignment
Professional Practice 1 Assignment
 
CSCM Chapter 9 sl as cscm
CSCM Chapter 9 sl as cscmCSCM Chapter 9 sl as cscm
CSCM Chapter 9 sl as cscm
 
Procurement management-plan template
Procurement management-plan templateProcurement management-plan template
Procurement management-plan template
 
SPECIFICATIONS
SPECIFICATIONSSPECIFICATIONS
SPECIFICATIONS
 
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...
IRJET- A Study on Use of Building Information Modelling for Cost Estimation P...
 
9. project procurement management
9. project procurement management9. project procurement management
9. project procurement management
 
Professional practice 1 report
Professional practice 1 reportProfessional practice 1 report
Professional practice 1 report
 
Guide to Construction Procurement Strategies
Guide to Construction Procurement StrategiesGuide to Construction Procurement Strategies
Guide to Construction Procurement Strategies
 
12 project procurement management
12 project procurement management12 project procurement management
12 project procurement management
 
Quality Management System at Construction Project: A Questionnaire Survey
Quality Management System at Construction Project: A Questionnaire SurveyQuality Management System at Construction Project: A Questionnaire Survey
Quality Management System at Construction Project: A Questionnaire Survey
 
Procurement in construction
Procurement in constructionProcurement in construction
Procurement in construction
 
Procurement system in the Indian construction industry issues and remedies
Procurement system in the Indian construction industry issues and remediesProcurement system in the Indian construction industry issues and remedies
Procurement system in the Indian construction industry issues and remedies
 
Technical feasibility ppt
Technical feasibility pptTechnical feasibility ppt
Technical feasibility ppt
 

Semelhante a Study on Procurement Method Selection Procedure in Construction Industry

IRJET- Decision Making in Construction Management using AHP and Expert Ch...
IRJET-  	  Decision Making in Construction Management using AHP and Expert Ch...IRJET-  	  Decision Making in Construction Management using AHP and Expert Ch...
IRJET- Decision Making in Construction Management using AHP and Expert Ch...IRJET Journal
 
Professional Practice 1
Professional Practice 1Professional Practice 1
Professional Practice 1Lee Pei Gie
 
IRJET- Review on Study of Factors Affecting Quality of Construction Project
IRJET- Review on Study of Factors Affecting Quality of Construction ProjectIRJET- Review on Study of Factors Affecting Quality of Construction Project
IRJET- Review on Study of Factors Affecting Quality of Construction ProjectIRJET Journal
 
Pp1 report
Pp1 reportPp1 report
Pp1 reportahmong4
 
Quality management at construction projects: Case study of a stormwater netwo...
Quality management at construction projects: Case study of a stormwater netwo...Quality management at construction projects: Case study of a stormwater netwo...
Quality management at construction projects: Case study of a stormwater netwo...IRJET Journal
 
IRJET- Importance of Proper Cost Management in Construction Industry
IRJET-  	  Importance of Proper Cost Management in Construction IndustryIRJET-  	  Importance of Proper Cost Management in Construction Industry
IRJET- Importance of Proper Cost Management in Construction IndustryIRJET Journal
 
Professional practice 1 (1)
Professional practice 1 (1)Professional practice 1 (1)
Professional practice 1 (1)tfkc1212
 
Estimating Seminar (QS)
Estimating Seminar (QS)Estimating Seminar (QS)
Estimating Seminar (QS)Hasif Alias
 
Pp1 assignment group 8
Pp1 assignment group 8Pp1 assignment group 8
Pp1 assignment group 8lohwenjun
 
Claims Management And Assessment Through Documentation
Claims Management And Assessment Through DocumentationClaims Management And Assessment Through Documentation
Claims Management And Assessment Through Documentationvivatechijri
 
IRJET- Construction Quality Management on Site
IRJET-  	  Construction Quality Management on SiteIRJET-  	  Construction Quality Management on Site
IRJET- Construction Quality Management on SiteIRJET Journal
 
Professional Practice I Assignment
Professional Practice I AssignmentProfessional Practice I Assignment
Professional Practice I Assignmentashleyyeap
 
Cbb 512 assignment_1
Cbb 512 assignment_1Cbb 512 assignment_1
Cbb 512 assignment_1Maatla Moadi
 
Time, Cost, and Quality Trade-off Analysis in Construction Projects
Time, Cost, and Quality Trade-off Analysis in Construction ProjectsTime, Cost, and Quality Trade-off Analysis in Construction Projects
Time, Cost, and Quality Trade-off Analysis in Construction ProjectsIRJET Journal
 
Factors Influencing Contractors Selection in Construction Projects
Factors Influencing Contractors Selection in Construction ProjectsFactors Influencing Contractors Selection in Construction Projects
Factors Influencing Contractors Selection in Construction Projectsijtsrd
 
Estamating seminar chapter 1 (QS)
Estamating seminar chapter 1 (QS)Estamating seminar chapter 1 (QS)
Estamating seminar chapter 1 (QS)Hasif Alias
 
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbtt
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbttUnit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbtt
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbttmanisha61981
 
Control procurement
Control procurement Control procurement
Control procurement Shereef Sabri
 
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET Journal
 

Semelhante a Study on Procurement Method Selection Procedure in Construction Industry (20)

IRJET- Decision Making in Construction Management using AHP and Expert Ch...
IRJET-  	  Decision Making in Construction Management using AHP and Expert Ch...IRJET-  	  Decision Making in Construction Management using AHP and Expert Ch...
IRJET- Decision Making in Construction Management using AHP and Expert Ch...
 
Professional Practice 1
Professional Practice 1Professional Practice 1
Professional Practice 1
 
IRJET- Review on Study of Factors Affecting Quality of Construction Project
IRJET- Review on Study of Factors Affecting Quality of Construction ProjectIRJET- Review on Study of Factors Affecting Quality of Construction Project
IRJET- Review on Study of Factors Affecting Quality of Construction Project
 
Pp1 report
Pp1 reportPp1 report
Pp1 report
 
Quality management at construction projects: Case study of a stormwater netwo...
Quality management at construction projects: Case study of a stormwater netwo...Quality management at construction projects: Case study of a stormwater netwo...
Quality management at construction projects: Case study of a stormwater netwo...
 
IRJET- Importance of Proper Cost Management in Construction Industry
IRJET-  	  Importance of Proper Cost Management in Construction IndustryIRJET-  	  Importance of Proper Cost Management in Construction Industry
IRJET- Importance of Proper Cost Management in Construction Industry
 
Professional practice 1 (1)
Professional practice 1 (1)Professional practice 1 (1)
Professional practice 1 (1)
 
Estimating Seminar (QS)
Estimating Seminar (QS)Estimating Seminar (QS)
Estimating Seminar (QS)
 
Pp1 assignment group 8
Pp1 assignment group 8Pp1 assignment group 8
Pp1 assignment group 8
 
KENA PRE.pptx
KENA PRE.pptxKENA PRE.pptx
KENA PRE.pptx
 
Claims Management And Assessment Through Documentation
Claims Management And Assessment Through DocumentationClaims Management And Assessment Through Documentation
Claims Management And Assessment Through Documentation
 
IRJET- Construction Quality Management on Site
IRJET-  	  Construction Quality Management on SiteIRJET-  	  Construction Quality Management on Site
IRJET- Construction Quality Management on Site
 
Professional Practice I Assignment
Professional Practice I AssignmentProfessional Practice I Assignment
Professional Practice I Assignment
 
Cbb 512 assignment_1
Cbb 512 assignment_1Cbb 512 assignment_1
Cbb 512 assignment_1
 
Time, Cost, and Quality Trade-off Analysis in Construction Projects
Time, Cost, and Quality Trade-off Analysis in Construction ProjectsTime, Cost, and Quality Trade-off Analysis in Construction Projects
Time, Cost, and Quality Trade-off Analysis in Construction Projects
 
Factors Influencing Contractors Selection in Construction Projects
Factors Influencing Contractors Selection in Construction ProjectsFactors Influencing Contractors Selection in Construction Projects
Factors Influencing Contractors Selection in Construction Projects
 
Estamating seminar chapter 1 (QS)
Estamating seminar chapter 1 (QS)Estamating seminar chapter 1 (QS)
Estamating seminar chapter 1 (QS)
 
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbtt
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbttUnit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbtt
Unit-4.pptxhhhghbfgvgtghvfgbbghbbhgfccvbtt
 
Control procurement
Control procurement Control procurement
Control procurement
 
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
IRJET- Factors Influencing Time and Cost Overruns in Indian Construction Proj...
 

Mais de IRJET Journal

TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...IRJET Journal
 
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURESTUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTUREIRJET Journal
 
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...IRJET Journal
 
Effect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsEffect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsIRJET Journal
 
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...IRJET Journal
 
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...IRJET Journal
 
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...IRJET Journal
 
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...IRJET Journal
 
A REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASA REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASIRJET Journal
 
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...IRJET Journal
 
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProP.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProIRJET Journal
 
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...IRJET Journal
 
Survey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemSurvey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemIRJET Journal
 
Review on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesReview on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesIRJET Journal
 
React based fullstack edtech web application
React based fullstack edtech web applicationReact based fullstack edtech web application
React based fullstack edtech web applicationIRJET Journal
 
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...IRJET Journal
 
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.IRJET Journal
 
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...IRJET Journal
 
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignMultistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignIRJET Journal
 
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...IRJET Journal
 

Mais de IRJET Journal (20)

TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
TUNNELING IN HIMALAYAS WITH NATM METHOD: A SPECIAL REFERENCES TO SUNGAL TUNNE...
 
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURESTUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
STUDY THE EFFECT OF RESPONSE REDUCTION FACTOR ON RC FRAMED STRUCTURE
 
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
A COMPARATIVE ANALYSIS OF RCC ELEMENT OF SLAB WITH STARK STEEL (HYSD STEEL) A...
 
Effect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil CharacteristicsEffect of Camber and Angles of Attack on Airfoil Characteristics
Effect of Camber and Angles of Attack on Airfoil Characteristics
 
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
A Review on the Progress and Challenges of Aluminum-Based Metal Matrix Compos...
 
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
Dynamic Urban Transit Optimization: A Graph Neural Network Approach for Real-...
 
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
Structural Analysis and Design of Multi-Storey Symmetric and Asymmetric Shape...
 
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
A Review of “Seismic Response of RC Structures Having Plan and Vertical Irreg...
 
A REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADASA REVIEW ON MACHINE LEARNING IN ADAS
A REVIEW ON MACHINE LEARNING IN ADAS
 
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
Long Term Trend Analysis of Precipitation and Temperature for Asosa district,...
 
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD ProP.E.B. Framed Structure Design and Analysis Using STAAD Pro
P.E.B. Framed Structure Design and Analysis Using STAAD Pro
 
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
A Review on Innovative Fiber Integration for Enhanced Reinforcement of Concre...
 
Survey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare SystemSurvey Paper on Cloud-Based Secured Healthcare System
Survey Paper on Cloud-Based Secured Healthcare System
 
Review on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridgesReview on studies and research on widening of existing concrete bridges
Review on studies and research on widening of existing concrete bridges
 
React based fullstack edtech web application
React based fullstack edtech web applicationReact based fullstack edtech web application
React based fullstack edtech web application
 
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
A Comprehensive Review of Integrating IoT and Blockchain Technologies in the ...
 
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
A REVIEW ON THE PERFORMANCE OF COCONUT FIBRE REINFORCED CONCRETE.
 
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
Optimizing Business Management Process Workflows: The Dynamic Influence of Mi...
 
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic DesignMultistoried and Multi Bay Steel Building Frame by using Seismic Design
Multistoried and Multi Bay Steel Building Frame by using Seismic Design
 
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
Cost Optimization of Construction Using Plastic Waste as a Sustainable Constr...
 

Último

OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...
OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...
OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...Soham Mondal
 
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINEMANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINESIVASHANKAR N
 
AKTU Computer Networks notes --- Unit 3.pdf
AKTU Computer Networks notes ---  Unit 3.pdfAKTU Computer Networks notes ---  Unit 3.pdf
AKTU Computer Networks notes --- Unit 3.pdfankushspencer015
 
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSAPPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSKurinjimalarL3
 
Introduction and different types of Ethernet.pptx
Introduction and different types of Ethernet.pptxIntroduction and different types of Ethernet.pptx
Introduction and different types of Ethernet.pptxupamatechverse
 
UNIT-III FMM. DIMENSIONAL ANALYSIS
UNIT-III FMM.        DIMENSIONAL ANALYSISUNIT-III FMM.        DIMENSIONAL ANALYSIS
UNIT-III FMM. DIMENSIONAL ANALYSISrknatarajan
 
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...ranjana rawat
 
Java Programming :Event Handling(Types of Events)
Java Programming :Event Handling(Types of Events)Java Programming :Event Handling(Types of Events)
Java Programming :Event Handling(Types of Events)simmis5
 
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...ranjana rawat
 
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...roncy bisnoi
 
Extrusion Processes and Their Limitations
Extrusion Processes and Their LimitationsExtrusion Processes and Their Limitations
Extrusion Processes and Their Limitations120cr0395
 
Top Rated Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...
Top Rated  Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...Top Rated  Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...
Top Rated Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...Call Girls in Nagpur High Profile
 
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...ranjana rawat
 
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...ranjana rawat
 
Introduction to Multiple Access Protocol.pptx
Introduction to Multiple Access Protocol.pptxIntroduction to Multiple Access Protocol.pptx
Introduction to Multiple Access Protocol.pptxupamatechverse
 
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur Escorts
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur EscortsCall Girls in Nagpur Suman Call 7001035870 Meet With Nagpur Escorts
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur EscortsCall Girls in Nagpur High Profile
 
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...ranjana rawat
 
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130Suhani Kapoor
 
Processing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxProcessing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxpranjaldaimarysona
 
College Call Girls Nashik Nehal 7001305949 Independent Escort Service Nashik
College Call Girls Nashik Nehal 7001305949 Independent Escort Service NashikCollege Call Girls Nashik Nehal 7001305949 Independent Escort Service Nashik
College Call Girls Nashik Nehal 7001305949 Independent Escort Service NashikCall Girls in Nagpur High Profile
 

Último (20)

OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...
OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...
OSVC_Meta-Data based Simulation Automation to overcome Verification Challenge...
 
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINEMANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
MANUFACTURING PROCESS-II UNIT-2 LATHE MACHINE
 
AKTU Computer Networks notes --- Unit 3.pdf
AKTU Computer Networks notes ---  Unit 3.pdfAKTU Computer Networks notes ---  Unit 3.pdf
AKTU Computer Networks notes --- Unit 3.pdf
 
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICSAPPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
APPLICATIONS-AC/DC DRIVES-OPERATING CHARACTERISTICS
 
Introduction and different types of Ethernet.pptx
Introduction and different types of Ethernet.pptxIntroduction and different types of Ethernet.pptx
Introduction and different types of Ethernet.pptx
 
UNIT-III FMM. DIMENSIONAL ANALYSIS
UNIT-III FMM.        DIMENSIONAL ANALYSISUNIT-III FMM.        DIMENSIONAL ANALYSIS
UNIT-III FMM. DIMENSIONAL ANALYSIS
 
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANJALI) Dange Chowk Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
 
Java Programming :Event Handling(Types of Events)
Java Programming :Event Handling(Types of Events)Java Programming :Event Handling(Types of Events)
Java Programming :Event Handling(Types of Events)
 
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(PRIYA) Rajgurunagar Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
 
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...
Call Girls Pimpri Chinchwad Call Me 7737669865 Budget Friendly No Advance Boo...
 
Extrusion Processes and Their Limitations
Extrusion Processes and Their LimitationsExtrusion Processes and Their Limitations
Extrusion Processes and Their Limitations
 
Top Rated Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...
Top Rated  Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...Top Rated  Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...
Top Rated Pune Call Girls Budhwar Peth ⟟ 6297143586 ⟟ Call Me For Genuine Se...
 
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...
The Most Attractive Pune Call Girls Budhwar Peth 8250192130 Will You Miss Thi...
 
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
(ANVI) Koregaon Park Call Girls Just Call 7001035870 [ Cash on Delivery ] Pun...
 
Introduction to Multiple Access Protocol.pptx
Introduction to Multiple Access Protocol.pptxIntroduction to Multiple Access Protocol.pptx
Introduction to Multiple Access Protocol.pptx
 
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur Escorts
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur EscortsCall Girls in Nagpur Suman Call 7001035870 Meet With Nagpur Escorts
Call Girls in Nagpur Suman Call 7001035870 Meet With Nagpur Escorts
 
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...
The Most Attractive Pune Call Girls Manchar 8250192130 Will You Miss This Cha...
 
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130
VIP Call Girls Service Kondapur Hyderabad Call +91-8250192130
 
Processing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptxProcessing & Properties of Floor and Wall Tiles.pptx
Processing & Properties of Floor and Wall Tiles.pptx
 
College Call Girls Nashik Nehal 7001305949 Independent Escort Service Nashik
College Call Girls Nashik Nehal 7001305949 Independent Escort Service NashikCollege Call Girls Nashik Nehal 7001305949 Independent Escort Service Nashik
College Call Girls Nashik Nehal 7001305949 Independent Escort Service Nashik
 

Study on Procurement Method Selection Procedure in Construction Industry

  • 1. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 340 STUDY ON PROCUREMENT METHOD SELECTION PROCEDURE IN CONSTRUCTION INDUSTRY Chandrashekhar R. Patil1, Prof. Mahaboobali Nadaf2 1Student M.Tech(Construction Technologgy), Chandrashekhar R. Patil, Dept. of Civil Engineering, Jain College of Engineering, Belagavi, Karnataka,India 2 Asst.Professor Mahaboobali Nadaf, Dept. of Civil Engineering, Jain College of Engineering, Belagavi, Karnataka, India ---------------------------------------------------------------------***--------------------------------------------------------------------- Abstract - This Project helps in selection of appropriate procurement method in the construction industry to achieve the requirements and needs of the clients and gives more detailed information about the how does the procurement system involved in the construction industry. This study consists of different procurement methods like traditional, design & build and management procurement, comparison of different procurement systems, influencing factors, effecting factors, key actions, variables , theoretical frame work, mechanism for analyzing the different procurement system, development of procurement strategy, advantages , detailed method selection procedure and case study. Brief study has carried out in the project work; about the procurement method selection procedure. Key Words: Procurement, Variables, Frame Work, Mechanism, Case Study 1.INTRODUCTION A procurement system can be defined as “an organizational system that assigns specific responsibilities and authorities to people and organizations, and defines the various elements in the construction industry”. It is not only applicable to developed market economics, but also construction industry development in less advanced economy. The procurement system benefits the organization to manage procurement process effectively and efficiently in construction industry. The system canassistanorganization to achieve successful outcome for their project with necessary guidance and support. It will also control therisks involved in the construction industry and minimize the cost variation problems.Theprocurementsysteminconstruction industry is useful in following ways:  It helps in preparing tender documents and contracts  Selection of contractors and consultants based on their earlier records  This system includes checklist for effective maintenance of the contract  It increases the efficiency and effectiveness of the management system by constant monitoring and reporting  The disputes arising are resolved with help of this system Procurement advice an appropriate contracting strategy, offering and preparation of tender documents, choice of experts and contractors, contract organizationandavoid the un-necessary discussions 1.1 Objectives of procurement system The goal of the procurement systemisforsuccessful completion and implementation of the project. Some of the objectives are mentioned below:  To carry out justifiably and truthfully  Perform assigned work in timely manner with honesty  Have to Satisfy the all rules of legislation and principles  To reach the all requirements of the client’s needs  Controls construction related dispute 1.2 Procurement activities and key actions Table-1: Activity and key action Activity Sub activity Key action 1 Defining the objectives for the procurement 1.1 Organize wide range of activities. To improve the title for procurement to recognize and define scope of the project. 1.2 Evaluation of economic value for planned procuremen t. For budgeting, it is necessary for evaluation of the economic value of the proposed contract.
  • 2. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 341 1.3 Scope This study helps in establishing a construction procurement system for: 1. Goods, services, engineering andconstructionwork relating to the construction industry in a fair, balanced, transparent, competitive and cost effective manner. 2. It deals with procurement methods which help to proper implementation and successful completion of the project as per client requirements. 3. It accomplishes future requirements, and develops the industry to give early and best adorable results to the clients with respect to cost, quality and time. 1.4 Objectives of the study Main objectives of the present project work are as follows: 1) Study of various procurement methods involved in the construction industry 2) To determine factors influencing the selection of procurement systems in construction industry 3) Mechanism for analyzing the different procurement system 4) Procedure to develop and implement a procurement strategy 5) To determine the suitable procurement method for Dr. Prabhu Halakatti hospital building, Belagavi 2. METHODOLOGY By referring different literatures, technical reports, case study and other resources related to the current study, an outline of the methodology of the present work has been discussed briefly below, to achieve the objectives of the project. • Study involves different methods of procurement system, influence of procurement methods on project performance, mechanism for analyzing different procurement system, procedure to develop and implement a procurement strategy • Comparison of different procurement systems and their advantages • Based on the studies, proposal have made on Dr. Prabhu Halakatti hospital building carried out during the period of internship, problems are analyzed and solved with the procurement system and few suggestions are made. 2.1 Procurement systems Different methods of procurements are a. Traditional b. Design and construct c. Management a. Traditional procurement method:Itistheoldesttypeof construction procurement as well as one of the most common types of procurement method. It is defined as a project delivery strategy, wherein two different companies will carry out all project processes. Contracts are mainly divided in to three types Lump sum contracts: Prior to the starting the construction project, the contract amount is determined with consulting various stakeholders. The amount of Lump sum contracts is decided on the basis of bill of quantities and thing which is not able to find can be found by accurate evaluation Measurement contracts: Here, only after thecompletionof the project and re-measurement, the precise amount is known and it is additionally alluded towards as re- quantification contracts. Cost reimbursement: It is as well recognized as cost plus contracts, wherein the contract amount is calculated based on actual cost of labour and materials also the profit and overhead charges are considered. Advantages of traditional procurement  Help full for the contractor to apply for the tender on the same premise.  Client can have immediate impact which can encourage high state of usefulness and enhance the quality in the design. Circumstances in which traditional procurement to be used are  Wherein the design consultant is necessary.  The designers and contractors are hired independently.  If superiority of the work is essential for the clients. b. Design and Construct Procurement: Here,theclientwill give all needs desires for the project and assigns different task to the contractor. The association of the D&C methods and relative freedom of the contractor helps the client in obtaining the best price for the project, which may lead to cost benefits. Advantages of design and construct procurement  Client can deal properly with one firm  Overlap of design and construction performance will minimize the project time CircumstancesinwhichD&Cprocurementtobeusedare  When project does not require any specialized development  Design scope is likely to change
  • 3. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 342  When project is technically difficult to understand c. Management Procurement system: This consists of management contracting and construction management. Management contracting: The management contractor is working with the clients. The contractors are involved at every stage of the construction and are responsible for works that are executed with direct contracts. Due to its flexibility, this type of contracts allow the clients to change the design during the construction process as well as the project can be started early and completed on time. Construction management: A contractor will pay amount as per the completely to control, build up a schedule and arrange the outline and development exercises, The administration contractual worker is chosen later than a vigilant determination procedure and is paid via administration prise. Various advantages have been recognized on CM approach summarized as follows  Construction management expertise involve met in the beginning of the project  Overlap of design and construction 2.2 Factors influencing the selection of procurement systems in construction industry External environment: Factors from the external environment consist of variables like market competition, information technology, regulatory environment, natural causes and globalization, politics, finance etc. Internal environment: This can be divided under three main factors such as project characteristics, client’s characteristics andclient’srequirement.Clientrequirements can be sub-divided into cost related factors, time related factors and quality related factors. Some of the important factors mainly influence while choosing of procurement system arebrieflyexplained below a) Socio–economic thought: It has derived from the four factors: political thought, government (public) or private segment venture, market or monetary condition and developing innovation. b) Client requirements: This factor incorporates: customer's particular prerequisites, political obstructions, globalization and customer's level of information. c) Capital cost/cash flow: This Factor clarifies the total variation; in any case, it is hard to clarify this component, since just a single variable impact upon it. Customer and fee related variable. If this componentmeasurescapital cost,itis identified with factors of customer necessities variables. d) Project characteristics: This Factor is obtained from variance that clarifies the total fluctuation. In particular, impact of the life cycle on venture, range and technical complexity of the venture. 2.3 A theoretical framework on influence of procurement methods on project performance Fig. 1 shows, a theoretical system that simplifies, the acquisition choice criteria, in order to help in discovering their effects on construction execution. All of the certainty would affect distinctively on duration, price and quality, dependent upon the appropriateness of the details as for a given acquirement technique. The level of impact of every fact on given venture can be dictated by allocating with a use of number utilizing a range of 1-7, where 1-3 demonstrates pessimistic impact on execution and 5-7 shows optimisticimpact,4asnoimpactor nonpartisan. Fig-1: Theoretical framework 2.4 Mechanism for analyzing the different procurement systems This settled structure clarifies and investigation both hard and flexible parts of authoritative administration, for example, procedure, structure, frameworks, shared values, staff and skills. It is additionally firmly related and appropriate to a venture conveyance approach,asthemodel is perceived for its all necessaries and substantial extension. The details of the Seven S Model and its extension and clarification for the construction project are:  Strategy: Describes as an arrangement in dispensing assets to accomplish recognized objectives at the time.  Structure: It characterizes a framework for the organization. Though, in construction project level, it is about the general venture delivery system, especially to organize the undertakings involved and its procedure of administration.  Systems: These are the standard procedures and methods followed within the association. It is comparative for the extent of works and employment exercises at the venture level.  Shared esteems: It eludes to the noteworthy implications or managing ideas that authoritative
  • 4. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 343 individuals share. The way of life of the overall management would decide the common values produced from alternate models at the venture level.  Staff: Describes as work force classes within the organization. This identifies with the level of capacities required for the workforce at the project level.  Skills: It alludes to the genuine level of abilities and capabilities of the representatives working for the organization. In the development setting, it is about the level of specialization required for the project delivery approach. 2.5 Procurement Strategies Procurement technique, which is regularly created amidthe assessment periods of a venture, is a key component for effective venture conveyance. The acquisition system is a core venture document, which shows the result of an exact acquirement alternative assessment undertaken by the project proprietor, to differentiate the suggested conveyance model and procurement technique for a venture while considering the venture's individual qualities, risk and conditions To build up a powerful acquirement methodology, it is critical to  Thoroughly comprehend the venture including key drivers, imperatives and dangers  Determine organization and market abilities and limit  Involve key partners and specialists at right time in the arranging and improvement process 2.5.1 Procedure to develop and implement a procurement strategy Appropriatelyprogramming theimprovementandexecution of the acquisition methodology with financing viewpoint, is the piece of good venture administration, as further discussed below. a) Informing the funding decision: It is essential that the procurement system is created in an opportune way, as offices might be required to present the points of interest of acquisition alternatives under contemplations to organizations, as a feature of the business case, in help of a speculation choice for the project. Last acquisition methodology will likewise should be endorsed by association before conveyance of the project. In creating acquirement procedures, the proprietors must permit adequate time for a capable investigation of all accessible obtainment alternatives, approval activities and surveys, and association endorsements. Organization will have their own particular procedures for procurement, to follow so as to get administration approval for the assumption, and whether this ought to happen at the same time with a choice on the favored procurement technique. b) Programming for development: venture conveyance,It can be depicted as the procedure by objective of a venture has acknowledged, it has to boost through a suitable acquisition strategy, to guarantee the necessary works are not postponed Programming the growth of the acquisition strategy is subsequently significant for a project administration perspective. To accomplish best possible timing, the obtainment strategy development process ought to initiate as right on time as venture lifecycle, as a major aspect of the venture's assessment and definition stages c) Programming for implementation: Guideline of the procurement strategy will usuallystartsattheinitial stageof the construction venture and it will carry out till the end of the phase, with that transition to function stage, it will be conditional on which kind of deliver model has considered. 3. CASE STUDY A Proposal is made by taking a hospital building as case study, through studying thevariousdocumentsanddifferent procurement system.Fromtheobservations,problemsfaced in the construction project are documented and suggestions were made for successful completion of project. Project title : Dr. Prabhu Halakatti Hospital Building Procurement method used: Traditional Lump Sum Project Value: Rs. 4, 27, 00,000 Contractor: Anoop Javalkar Client: Dr. Prabhu Halakatti Architect: Sangolli and Associates Project Overview The choice to add a Traditional Lump Sum procurement strategy on this venture is intensely affected through the diverse features of the venture. All things considered, adequate time and assets were dispensed to ensure definite plan and determinations has framed. Moreover, it is an interesting undertaking wherein, the design and requirements must be precise with particular criteria. It is consolidated with the TLS strategy for acquisition proposed to contractual worker with offering of the venture so that, procurement determination handle for this venture is moderately straight-forward. With construction is expected to finish by 2017 with total cost of Rs 4.27cr. The new heart hospital center will provide the best heart related treatment accessible in the Belagavi city and considerably decrease the waiting time forpatients.
  • 5. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 344 The hospital right now care for around 1200 heart patients utilizing distinctive treatment every year, with 4000 treatment will visit, the opening of the latestHospital center, extra 200 heart patients will be there dealt with every year. Detailed Documentation: More attention on the plan and design was necessary. Ventures relating to health are more intricate than the most projects carried out by architects. Detailed documentation is taken into thought for expectations works and its coordination into existing structures was likewise of critical significance. The acquirement technique embraced for this venture must be adequate to help the contribution of reasonable advisors. High Quality End Product: Effect of contributing adequate duration and assets, in the direction of deliver complete records at the major stage of plans and particular, this point of scheduling will deal by means of the coveted necessity with high quality final result. The significance of a high quality venture will be highlighted bytheventuresupervisor A Balance of Risk between Client and Contractor: Importance of time and assets interested ina completeset of plans and determinations, among each of the offering that contractor offers would guarantee a more focused choice process and value affirmation of the venture. The TLS strategy, being an attemptedandtriedtechniquefor acquisition alternative for venture proprietor and the market encouraged a decent balance of risk between the customer and contractors. Problems occurred during construction  Lagging in supply of deign during construction progress  Delay in project due to in-sufficient supply of materials  There is not much proper communication between clients, contractor and management team  Over run of time due to making changes in designin middle of construction  Variation in cost due to market rates andchangesin material selection by client  Improper management makes failure of scheduled plan Project Procurement Selection Process The procurement method selection procedureisdetermined by means of the case project, the project is based on typical criteria. In this example, the client is the Dr. Prabhu Halakatti, has given the proposal for new hospital building with disabilities. Above problems have influenced to choose suitable procurement method, it is determined with the following process. Step 1: Identifying project objectives and constraints Objectives of projects:  Proper programmingandphasingshouldbeontime  Design criteria has to meet the needs of the client  Projects have to complete within the agreed rate  There should not be any over run or delay in the project  Cost conviction will berequiredprecedinginitiation of development Project Constraints:  Programme Constraints: Well information about the hospital building designs are prepare for the entire project to check clearly completion of the work at the different stages of construction.  Planning: The design proposition has satisfied the requirements of the planning experts and local partners in the advancement.  Site Availability: The site ought to be accessible in the best possible area  Site Condition: Site had clearlysurveyedbeforethe start of project, by under taking it as a major aspect of plan improvement.  Degree of Client Involvement: It is the most important in the construction management and Dr. Prabhu Halakatti involvement in the all stages of construction process.  Flexibility for Change during Design and Construction: Design of the building had carried earlier & found good prise certainty, hence there is not required to change during the execution stage. The procurement options examined here and alternative procurement methods identified based upon preliminary discussions are: a. Traditional b. Design and Build c. Management Step 2: Identify Procurement Selection Criteria Identification of Procurement Selection Criteria carried on the following basis, Time: Early completion of the project is necessary Certainty of time: Project completion time is most important Certainty of cost: Firm prise needed before commitment to construction Price competition: Selection of the construction team by price competition as needed
  • 6. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 345 Flexibility: Variations are needed after work has begun on- site Complexity: Building need to be highly specialised, technologically advanced Quality: High quality of the product,intermsofmaterial and workmanship and design concept are required Responsibility: Client had the more accountabilityfrom the architecture and cost consultants. Risk: The transfer of the risk of cost and time slippage from the client is vital Step 3: Weightages of Client Criteria and Procurement Methods The procurement assessment criterion for the client’sneeds and for each procurement methods has clearly found below Table-2: Determination of the importance of client criteria for the project Procurement Assessment Criteria Weig hting Time: Is early completion required? 5 Certainty of time: Is project completion on time important? 5 Certainty of cost: Is a firm price needed before any commitment to construction given? 3 Price competition: Is the selection of the construction team by price competition important? 3 Flexibility: Are variations necessary after work has begun on-site? 4 Complexity: Does the building need to be highly specialized, technologically advanced or highly serviced? 5 Quality: Is high quality of the product, in terms of material and workmanship and design concept important? 4 Responsibility: Is single point of responsibility to the client from the designers and cost consultants desired? 3 Risk: Is the transfer of the risk of cost and time slippage from the client important? 2 Table-3: Criteria weighting with respect to procurement method Procurement Assessment Criteria Traditional Procurement (P1) D & B Procur ement (P2) Manageme nt Procureme nt (P3) Time 3 5 4 Certainty of time 3 5 4 Certainty of cost 2 4 4 Price competition 4 3 3 Flexibility 4 4 3 Complexity 4 5 4 Quality 3 4 4 Responsibility 2 5 4 Risk 2 3 2 Table-4: Weighted procurement method scoring table From the above results can say traditional andmanagement procurement methods are less scored than D&B procurement method. Hence, D&B can be considered as the best suitable procurement method for the proper implementation of the project to get successful out comes as per client needs. Procureme nt evaluation criteria Weig htage (W) Traditiona l Procurem ent W x P1= D&C procurem ent W x P2= Manageme nt procurem ent W xP3= Time 5 15 25 20 Certainty of time 5 15 25 20 Certainty of cost 3 6 12 12 Price competitio n 3 12 9 9 Flexibility 4 16 16 12 Complexity 5 20 25 20 Quality 4 12 16 16 Responsibi lity 3 6 15 12 Risk 2 4 6 4 Σ = Rank 106(3) 149(1) 125(2)
  • 7. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 346 Step 4: Procurement Appropriateness Chart Below tables gives a suggestion on the suitability of every choice against the objectives and key criteria for the project. Table-5: Time Time Traditional Procuremen t D&B Procuremen t Managemen t Procuremen t Completion date certainty Poor Good Average Traditional procurement takes more time to complete the project Ability to meet current programme Poor Good Average The program has to give sufficient time for characterizing the customer’s necessities. Facility to phase constructio n Average good Average Opportunity for contractual worker contribution to preplanning for staged conveyance Table-6: Cost Cost Traditional Procurement D&B Procurement Management Procurement Fixing the total amount of the project before making the any bonds. Average Good Average Conventional technique gives agreatlevelofprice sureness furnish so as to complete outline is delivered preceding to offering Similarly with D&C gives a huge level of rate assurance giving the customer’s necessities is completely characterized up to execution phase. Shifting of amount related problems Poor Average Poor In D&C configuration hazard will howeverremain with the customer through the plan group. Under customary frameworks danger of configurationis held by the customer. In D&C design risk will however stay with the client through the design team. Under traditional systems risk of design is retained by the client. Focused offering in current market situations Average Good Average The D&C seems, by all accounts, to be the mainly appealing alternative for the present market circumstance. Table-7: Quality Step 5: Procurement Review Session Every perspective from the above Table5to7isexaminedat the procurement review session. The following points were audited in connection with elective procurementtechniques accessible: Client will be monetarily risk hesitant: D&Cwill givemost significant cost assurance at every key choice period. Client will discourage late changes: D&C is a lesser amount of adaptable to tardy changes. Therefore, it is favoured more. An unmistakable and subtle element of Client's prerequisites up to proper level will be required. Programme is essential: For early complete,D&Cwill offer the best program favourable circumstances. Quality is vital: D&C technique gives the best chance to design quality control, atanexpandedcostrisk evaluatewith D&C. D&C can give a satisfactory level of plan. Market conditions: A prior approach and prior participation of the contractor is valuable in present economic situations. Partnering: The Client support's partnering arrangements; D&C will bring early contractual workerparticipationand so it proposes the most excellent alternative option to associates. Preferred Option The assent favored choice at this stage is a Design and Construct procurement method. Key contemplationsare the Quality Traditional Procureme nt D&B Procurem ent Management Procurement Capacity for temporary worker to include an assess plan improvement. Average Good Average Conventional: Contractor hasparticipatedindesign, it may cause a few issues as far as zones, for example, buildability. Offering will get huge quality at points of interest. D&B: Gives most extreme capacity for contractual worker to include an incentive in outline. Adaptable to suit modify instructions Average Average Poor Development organize changes ought to be stayed away from while embracing D&C Single point duty regarding design and development Poor good Average In customary the outline and development duties are divided Capacity to manage/react to location circumstances Good Good Average Temporary workers can examine the location surroundings completely
  • 8. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 347 possibilities, to achieve the finish of the procurement method choice in development of project Advantages  Ability of the design team and customer to have an immediate impact. This will achieve a high level of usefulness and upgrade the nature of the general design.  Client is certain about the venture's cost at the conferring phase of the agreement.  Differences in the venture are generally simple to direct. Limitations  Incomplete reports and configuration can compromisecostconviction andincrementtheodds of troubles that might occur.  Restricting the contribution of design or arranging skill from the contractual worker may not be to the greatest advantage of the venture. Lessons Learned  Enough allotment of assets is necessary to guarantee design and documentationoftheventure will conclude at the calling for tender phase of the venture.  For superlative activities, for example,those related with health, the traditional method of procurement gives the customer the choice for alternatives in expert advisors to help with the outline.  This can likewise be a convenient procedure and if the documentation is notfinished,theadvantagesof cost certainty can be extreme. Suggestions  By implementing the D&Cprocurementsystem,one can achieve the requirements of the client’s andcan complete the project on time.  Design and build method give the appropriate solution for the above problems occurred on construction organization.  The procurement system should be used to give specific responsibility to participants in the construction project.  The suitable system must be selected, to complete the project successfully and efficiently. 4. CONCLUSIONS AND FUTURE SCOPE  It has proposed, choice of appropriate procurement method is the beginning step to achieve goals in construction related projects.  Mainly, three most three critical parameter of project performers are Cost, time and quality.  More effective in monitoring and control to accurate implementation and to progress the work  Who are related to the construction industry, they may be from public or private sector must be well known about the different procurement system, hence it will support to get good results  Client's authentic needs, necessities, destinations and project objectives should be properly suggested to the project group, keeping in mind the end goal is to make proper procurement strategy  A apparent, common system has to built up at an early phase of the project which will decide extensively what has be done, how it has be done, by whom it must be done, where it have to be done and when it must be properly finished  Improved utilize and equivalence of data innovation is probably going to be the key, all together for development industry to have the capacity to meet the administrative, specialized and social difficulties.  Improving the procurement strategy in building administration will get more advantages to deal with workforce, proprietor of the building, and the clients who are identified with support industry. Future scope of study This study can be extended to other procurement system such as  E-procurement  Collaborative  Joint venture  Private financing initiative REFERENCES 1) Associate Prof. Dr. Anuar Alias et al., Selection of Procurement Method for Building Maintenance Management 2) Christopher N. Preece, Improving Construction Procurement Systems Using Organizational Strategies, Vol. 11, No. 1 (2014). 3) David Baccarini et al., Building Procurement Methods, Research ProjectNo:2006-034-C-02,June 2008 4) Dissanayaka Sunil et al., Comparing Procurement And Non-Procurement Related Contributors to Project Performance, 1998. 5) Mathonsi, M. D. et al., Factors Influencing The Selection Of Procurement Systems In The South African Construction Industry ISSN 1993-8233,Vol. 6(10), 14 March, 2012, pp. 3583-3594. 6) Peter Bamford, Buildingand Construction Procurement Guide, ISBN 978-1-925037-19-7,
  • 9. International Research Journal of Engineering and Technology (IRJET) e-ISSN: 2395-0056 Volume: 04 Issue: 08 | Aug -2017 www.irjet.net p-ISSN: 2395-0072 © 2017, IRJET | Impact Factor value: 5.181 | ISO 9001:2008 Certified Journal | Page 348 Austroads Publications Number AP-G92-14(2014), pp. 56. 7) Shamil Naoum.et al., Critical review ofprocurement method research in construction Journals, No.6-13 (2015). 8) Zuleha R. Kadima.et al., An Analysis of procurement procedures on the implementation of government construction projects in Kenyan public Universities, ISSN: 2278 – 0211, Vol 2 Issue 11, November, 2013. BIOGRAPHIES Mr. Chandrashekhar R. Patil Pursuing M.Tech (Construction Technology) Jain College of Engineering, Belagavi, Karnataka, India. Prof. Mahaboobali Nadaf Guide & Asst. Professor at Jain College of Engineering, Belagavi, Karnataka, India.